P.K. Bahri, J.
(1) This petition has been filed under Sections 8 & 20 of the Arbitration Act for seeking direction for filing of the arbitration agreement and for reference of the disputes mentioned in the petition to the arbitrator to be appointed in accordance with the arbitration clause.
(2) The petitioner had entered into a contract with the respondents for the work of 'construction of effluent disposal channel out fall structure and Wbm roads at MRP' operating through Mathura Refinery Project. This work was awarded to the petitioner vide letter dated October 20, 1977, with the stipulation that period of completion would be 20 months reckoned from the date of handing over of the site. It is averred that later on certain discussions took place and it was agreed on December 7, 1977, that the site shall, however, be handed over to the contractor progressively and the entire stretch of land within a maximum period of six months from the date of letter of acceptance. So, it is aveired that the entire site was to be handed over latest by April 19, 1978 and it was assured that at least one-third of the land would be made available for execution of the work up to January 15, 1978. The petitioner has pleaded that, in fact, the respondents could make available only 600 meters of stretch of land against total land of 5,100 meters up to May 10, 1978. So, due to this breach of the term of the contract by the respondents, the petitioner is stated to have suffered losses for which' the petitioner claims damages. It is pleaded that the entire work was completed by the petitioner on September 15, 1980, to the entire satisfaction of. the respondents in terms of the contract. The petitioner had furnished security deposit of Rs. 3,27,000.00 which was liable to be refunded on March 14, 1981, i.e. excluding the six months period of liability of the petitioner for maintenance of the work from the date of the completion. The petitioner is also stated to have put up a claim for the payment of Rs.7,72,410.00 . The petitioner has pleaded that instead of releasing the security of Rs. 3,27,000.00 , the respondents required the petitioner on April 3,1981, to extend the validity period of the bank guarantee for a period of three months and the respondents were bent upon not to release the security deposit unless the petitioner agreed to reduce his claim. It is pleaded that the petitioner out of coercion agreed to receive any payment whatsoever offered by the respondents and the petitioner was then refunded his amount due to the petitioner on the basis of the work already done and Rs. 1,00,000.00 out of the claim of Rs. 7,72,410.00 . The petitioner then served a notice on the respondent for claiming Rs. 6,72,410.00 and on failure of the respondent to pay the said claim, the petitioner has invoked the arbitration clause for reference of the disputes to the arbitrator. The details of the claim are mentioned in para 26 of the petition. It is mentioned that the petitioner is entitled to payment on account of idle labour charges with effect from May 30, 1978 to June 15, 1978 which come to Rs. 22,035.00 and the claim against the increase in the cost and material, transportation etc. the amount claimed was Rs. 7,50,375.00 and after deducting Rs. l,00,000.00 already received, the petitioner has now set up his claim for Rs. 6,72,410.00 . It is evident from the perusal of the petition that this claim is for damage incurred by the petitioner on account of respondent not making available the site to the petitioner within the stipulated period.
(3) The respondents has contested the petition pleading that the petition is not maintainable as is hit by the provisions of Section 69 of the Indian partnership Act and on merits, it is pleaded that in view of the terms of the contract, particularly clauses 66.1.0 and clause 126.96.36.199. the petitioner was bound to notify the claim to the Engineer-in-Charge within ten days and the petitioner having not notified the claim in accordance with the main clause 188.8.131.52, the claim for damages is not covered by the arbitration clause 184.108.40.206.
(4) Another plea taken is that the petitioner has accepted Rs. 1,00,000.00 on full and final satisfaction of his claims and thus, is not entitled to raise any other claim which could be referred to arbitration.
(5) Following issues were framed:
1.Is the petitioner a registered partnership firm and is 'the name of Shri Mahavir Prasad Bansal entered in the register of Registrar of firms as a partner thereof?
2.Whether the claims of the petitioner or any of them are notified claims within the scope of the arbitration agreement?
3.If issue No. 2 is proved, does the arbitration agreement stand discharged and extinguished as alleged by respondent No. I?
(6) Issue No. I The matter was directed to be decided by affidavits. Shri M.P.Bansal has filed the affidavit in which he has mentioned that the petitioner is a registered partnership firm and he is one of the registered partners. In view of this affidavit which is not controverter, counsel for the respondent has not raised any contentions based on provisions of Section 69 of the Indian partnership Act. So, this issue is decided in favor of the petitioner.
(7) Issues NOS. 2&3 Issues Nos. 2 & 3 would be dealt with together. In order to appreciate the contention being rased before me on these issues, it is appropriate to refer to relevant clauses of the contract. Clause 220.127.116.11 reads as follows:
'SHOULD the Contractor consider that he is entitled to any extra payment or compensation in respect of the works over and above the amounts due in terms of the contract as specified in clause 18.104.22.168 hereof or should the Contractor dispute the validity of any deductions made or threatened by the owner from any penning account bills or any payments due to him in terms of the contract, the contractor shall forthwith give notice in writing of his claim in this behalf to the Engineer-in-Charge and the Site Engineer within 10 (ten)days from the date of the issue of orders or instructions relative to any works for which the Contractor claims such additional payment or compensation, or on the happening of other event upon which the contractor bases such claim, and such notice shall give full particulars of the nature of such claim, grounds on which it/is based, and the amount claimed. The Contractor shall not be entitled to raise any claim, nor shall the owner anywise be liable in respect of any claim by the Contractor unless notice of such claim shall have been given by the Contractor to the Engineer-in-Charge and the Site Engineer in the manner and within the time aforesaid, and the Contractor shall be deemed to have waived any or all claims and all his rights in respect of any claim not notified to the Engineer-in-Charge and the Site Engineer in writing in the manner and within the time aforesaid'.
THE arbitration clause contained in Clause 22.214.171.124 reads as follows: Subject to the provisions of Clauses 126.96.36.199 and 188.8.131.52 hereof, any dispute or difference between the parties hereto arising out of any notified claim of the Contractor included in his Final Bill in accordance with the provisions of Clause 184.108.40.206 hereof and/or arising out of any amount claimed by the owner (whether or not the amount claimed by the owner or any part thereof shall have been deducted from the Final Bill of the Contractor or any amount paid by the owner to the Contractor in respect of the work) shall be referred to arbitration by a Sole Arbitrator selected by the Contractor from a panel of three persons nominated by the General Manager.'
(8) The learned counsel for the respondents has contended that unless and until the Contractor had notified his claim in consonance with the provision of Clause 220.127.116.11, the claim of the petitioner is not arbitrable in view of the clear wording of the arbitration clause.
(9) The learned counsel for the petitioner, on the other hand, has contended that it was not incumbent on. the part of the petitioner to have notified any such claim to the Engineer-in-Charge or the Site Engineer as required by Clause 18.104.22.168 and the claim in question is covered by the arbitration clause and it is for the arbitrator it decide the merited of the claim. The matter is not rest integra as these two clauses appearing in the usual contracts of Indian Oil Corporation Limited came up for consideration in two judgments of this Court, one given in Suit No. 697-A/83, M/s. Uttam Singh Duggal & Co. (P) Ltd. Vs Indian Oil Corporation Limited & Another, decided on January 8, 1985, by D.P. Wadhwa, J. and the other given in Suit No. 2399-A/85, M/s Associated Hybilds (P) Ltd. Vs Indian Oil Corporation Limited, decided on October 15, 1987, by B.N. Kirpal, J.. In the case of Uttam Singh Duggal (supra) the Contractor has put up the claim alleging that there had occurred a breach of contract by the Indian Oil Corporation in furnishing the drawings. The Contractor in that case is alleged to have suffered damages for idle labour and due to escalation of prices of material and labour as the Corporation had committed breach of contract in not furnishing the drawings within the stipulated periods which delayed the execution of the work by the contractor. In the said case also, the plea was taken by the Corporation that the Contractor had failed to notify the claims in accordance with clause 6.6.10 and thus, the dispute was not arbitrable in accordance with the arbitration clause 9.1.00.
(10) After dealing with all the contentions which could possible be raised in a very extensive judgment, the learned Judge came to the conclusion that unless and until the claim is notified in terms of clause 22.214.171.124 of the arbitration clause mentioned above. In the case of M/s Associated Hybilds (P) Ltd. (supra), again the Contractor had set up the claim for damages on account of the Corporation not making available the site for the work within the stipulated period. The learned Judge after referring to the similar clauses clearly held that unless the claim is notified in terms of clause 126.96.36.199 the claim cannot be referred to arbitration under clause 188.8.131.52. In both the cases the petition under Section 20 was dismissed.
(11) In the present case also, admittedly the petitioner had not notified his 'claim in terms of clause 184.108.40.206 and thus, the same cannot be referred to for arbitration in view of the very wording of arbitration clause 220.127.116.11. So, I hold that the claim of the petitioner cannot be referred for arbitration. Issues are decided against the petitioner.
(12) Relief In view of the decision in issues 2 & 3 the petition is liable to be dismissed. I dismiss the petition, but in view of the peculiar facts of the case I leave the parties to bear their own costs.August 2,1991,P.K.BAHARI J.