U.S. Supreme Court Davis Sewing Machine Co. v. United States, 273 U.S. 324 (1927)
Davis Sewing Machine Company v. United States
Argued January 6, 1927
Decided February 21, 1927
273 U.S. 324
APPEAL FROM THE COURT OF CLAIMS
A claim for profits anticipated from the performance of a contract with the government cannot be based on delays caused by changes made by the government when, under the contract itself, the remedy for such delay was to be an extension of time to the contractor, and when the contract was terminated by a supplemental agreement expressly releasing all claims for such profits. P. 273 U. S. 325 .
60 Ct.Cls. 201 affirmed.
Appeal from a judgment of the Court of Claims disallowing in part a claim under a contract to make Very pistols for the government.
MR. JUSTICE SUTHERLAND delivered the opinion of the Court.
This suit was brought to recover upon a contract between appellant and the United States to manufacture a large number of Very pistols. It was stipulated in the contract that the government might terminate it in whole or in part at any time, and, in that event, certain enumerated payments were to be made, not including, however, prospective profits upon uncompleted articles. The contract provided that, upon written notice, the government
might make changes in the specifications, increased cost, if any, to be paid, and, for any delay in consequence thereof, a corresponding extension of time for the performance of the contract to be allowed. After the Armistice, appellant was requested to suspend work, with a view to the negotiation of a supplemental contract providing for the cancellation, settlement, and adjustment of the existing contract. Subsequently appellant filed a claim, and a partial payment supplemental contract was executed by which the government agreed to make appellant an advance payment and speedily determine and pay certain specified items. Appellant agreed that it would not perform further work or services, or incur further expense in connection with the performance of the uncompleted part of its original contract, and expressly waived
"all claim to the prospective profits which he [it] might have made from the performance of that portion of said original contract which under the terms of this supplemental agreement will not be performed."
The advance payment was made, and the court below found that, after its deduction and the allowance of another credit, there was due appellant a balance of $14,192.25, and it refused to allow appellant anything for profits which appellant would have realized if the contract had been performed. Judgment was rendered accordingly. 60 Ct.Cls. 201. The appeal to this Court was taken under the law as it stood prior to the Act of February 13, 1925, c. 229, 43 Stat. 936.
Appellant contends that changes made by the government in the specifications, etc., occasioned such delay as to preclude full operations under its contract prior to the termination thereof, and that it should have judgment for the profits which it would otherwise have made. The conclusive answer to this contention is two-fold: (1) the contract itself specified the remedies, to which appellant would be entitled in the event of changes in or a complete or partial termination of the contract, among which prospective
profits were not included, and (2) appellant, by the terms of the supplemental contract, expressly released all claims to such profits.